Clause 8 contains all the fundamental provisions relating to the start of the Works, the Time for Completion, delays and the entitlement of the Contractor to an extension of time and of the Employer to delay damages, and finally the circumstances in which a suspension of the Works can occur and the implications for the Parties.
Much has already been written concerning the new FIDIC forms of contract published in December 2017. They are approximately 50 % longer and sought to set out the various procedure in much greater detail with the object of both encouraging good practice and reducing the scope for disputes. Numerous minor amendments have also been made. The purpose of this article is to look in more detail at the provisions dealing with Variations, these being amongst the most frequently scrutinised in practice.
FIDIC’s 2017 editions introduced a new Claims management system in clause 20 that channels Claims through two very different procedures. One of them is very simple and involves almost no risk whereas the other will require investment of significant project resources, will take the parties a considerable amount of time to resolve and carries fatal consequences if not followed properly. It has therefore become a priority for anyone handling this Claims management system to understand how clause 20.1 sorts the different types of Claims and to recognise that the classification scheme is not as straightforward as the wording of the Contract suggests, as explored in this article.
Clause 14 deals with all aspects of payment. It also deals with the Statement at Completion, the Final Payment Certificate, Discharge and Cessation of the Employer’s Liability. The Clause provides that this is a re-measurement contract and that the quantities stated in the Bill of Quantities are estimated. There is provision for an advance payment to be made to the Contract. Applications for Interim Payment Certificates are made monthly and these must be supported by documents and a report on progress. Unless the amount assessed is less than the minimum amount set out in the Appendix to Tender, the Engineer has 28 days to issue an Interim Payment Certificate, which states the amount the Engineer fairly determines to be due. The Employer thereafter has an obligation to pay the amount certified, in the currencies named in the Appendix to Tender. In the event that payment is not received the Contractor can claim financing charges compounded monthly. Fifty per cent of the retention monies are paid when the Taking-Over Certificate is issued. Where there are Sections then a proportion is paid. The balance of retention is paid on the expiry of the latest Defects Notification Period or, where there are Sections, a proportion at the expiry of the Defects Notification Period for that Section. Within 84 days of receiving the Taking-Over Certificate the Contractor submits a Statement at Completion. This must include an estimate of all sums which the Contractor considers due. Within 56 days of receiving a Performance Certificate, the Contractor submits a Final Statement. The Contractor must also submit with the Final Statement a written discharge which confirms that the total of the Final Statement represents full and final settlement of all moneys due. The Engineer then issues to the Employer a Final Payment Certificate. The Contract states that the Employer shall have no liability to the Contractor except to the extent that the Contractor has included an amount expressly for that matter in the Final Statement and also the Statement at Completion.
Clause 3 deals with the duties and obligations of the Engineer and his assistants. Sub-Clause 3.1 deals with the role and duties of the Engineer. The Engineer is deemed to act for the Employer. The Engineer has no authority to relieve the Contractor of his duties, obligations or responsibilities under the Contract; nor can the Engineer amend the Contract. Under Sub-Clause 3.2 the Engineer can delegate authority to any assistants; however, the Engineer cannot delegate the responsibility to make Determinations. Under Sub-Clause 3.3 the Engineer may issue instructions or modified Drawings at any time, which are necessary for the execution of the Works. If the instruction constitutes a Variation, then it is dealt with under Clause 13 [Variations and Adjustments]. The Contractor is required to comply with any instruction given by the Engineer or delegated assistant. Sub-Clause 3.4 deals with the replacement of the Engineer. The Employer must not replace the Engineer with someone against whom the Contractor raises reasonable objection. Sub-Clause 3.5 deals with Determinations. When making a Determination the Engineer should consult with each of the Parties and, if agreement cannot be reached, make a fair determination in accordance with the Contract, taking due regard of all relevant circumstances. Both Parties are required to give effect to any Determination unless, or until, it is revised under Sub-Clause 20.1 [Claims, Disputes and Arbitration].
In London last week, FIDIC launched its Second Editions of the Red, Yellow and Silver Books. They are big, weighing in at almost a kilo each. The general conditions cover 106 pages with more than 50,000 words, over 50% longer than the 1999 forms. Many improvements have been made, addressing issues that have emerged since 1999. Fans of Dispute Boards will be pleased to see that all three books now have standing boards with more emphasis on dispute avoidance; and that appointment of DB members and enforcement of their decisions have been made easier. Disputes and Arbitration are now dealt with in a separate chapter 21. Here are the most interesting changes to the Yellow Book.
Click through to read Corbett & Co.'s helpful commentary on FIDIC 1999 book Clause 15
