FIDIC 2022 Reprints: 10 Key Areas Of Change In The FIDIC Red Book 2017

FIDIC ‘launched’ the FIDIC 2022 reprints at the FIDIC International Construction Users’ Conference 2022, in London. The reception to the changes was mixed – some embraced the clarity; others questioned the significance and cost. This article draws your attention to 10 of the key areas of change in respect of the FIDIC Red Book 2017 including the definition of Claim, matters to be agreed or determined, the definition of Dispute and Exceptional Events.

By |18/01/2023|Adjudication / Dispute Boards / ADR, Design, Dispute Boards, featured, Knowledge Hub|Comments Off on FIDIC 2022 Reprints: 10 Key Areas Of Change In The FIDIC Red Book 2017

FIDIC Changes in Legislation and Covid-19: Compelled by Law or Just Doing Your Job?

Up until the spring of 2020, a FIDIC 1999 Sub-Clause 13.7 [Adjustments for Changes in Legislation][1] claim was just one of many issues to be resolved, for example, in a delay and disruption claim or a Cost claim. However, the focus it receives in the context of Covid-19 is drastically different. Many in the industry are using the changes in legislation provision to seek financial compensation in a situation that would otherwise potentially only attract an extension of time.[2] Awarding Cost for Covid-19 events regardless of the circumstances may seem to some (Contractors mostly, though there are Employers and Engineers who agree) like the appropriate thing to do, but whether it is correct according to the Contract is a different question.

By |23/09/2021|Covid, Delay, featured, Knowledge Hub|Comments Off on FIDIC Changes in Legislation and Covid-19: Compelled by Law or Just Doing Your Job?

Changing Tack

A contract may require a party giving notice of a claim to specify the contractual or legal basis of that claim in the notice (or the supporting particulars). What if that party states a contractual or legal basis for the claim but later (perhaps with the benefit of additional information or because of advice from its lawyers) changes its mind or wants to include further contractual or legal bases? This was considered by the Hong Kong Court of Appeal in Maeda Corporation and China State Construction Engineering (Hong Kong) Limited v Bauer Hong Kong Limited [2020] HKCA 830. It found that a subcontractor could not change the contractual basis for its claim once the time period for providing such notice had expired. What, if any, impact will this decision have on the FIDIC forms of contract?

By |07/05/2021|Arbitration, featured, Knowledge Hub|Comments Off on Changing Tack

FIDIC 1999 Books – Commentary on Clause 17

Although Clause 17 is titled ‘Risk and Responsibility’ it also sets out other provisions relating to indemnities, limitation of liability and, unusually, the specific topic of intellectual and industrial property rights. The clause provides that the Contractor assumes responsibility and bears the risk for the care of the works during execution and for remedying any defects during the Defects Notification Period. Risk transfers to the Employer on issue of the Taking–Over Certificate to the extent of works defined as being completed. Generally, in construction contracts ‘risk’ is understood to mean an event or circumstance which causes delay, loss or damage to the Works. A risk can be said to be Employer caused, Contractor caused or neutral. The purpose of risk allocation is to determine which party bears the risk for such events. The Contractor may be required to remediate the damage at his own cost or the Employer may be required to pay for the damaged works. It has been stated that the “FIDIC standard forms are generally recognised as being well balanced because both parties bear parts of the risks arising from the project.”

By |04/04/2019|Delay, English Law, featured, Knowledge Hub|Comments Off on FIDIC 1999 Books – Commentary on Clause 17
Go to Top