This article examines the conflict between the prevention principle and FIDIC notice provisions. Traditionally, employers cannot enforce obligations causing delays, but modern contracts demand strict notice compliance. Recent cases favor enforcing notice regimes, even for employer-caused delays, sparking fairness concerns.
If the parties to a FIDIC contract cannot agree on
As one of the drafters of the Green Book 1999,
FIDIC ‘launched’ the FIDIC 2022 reprints at the FIDIC International Construction Users’ Conference 2022, in London. The reception to the changes was mixed – some embraced the clarity; others questioned the significance and cost. This article draws your attention to 10 of the key areas of change in respect of the FIDIC Red Book 2017 including the definition of Claim, matters to be agreed or determined, the definition of Dispute and Exceptional Events.
The FIDIC 2017 forms first appeared at the December FIDIC Users’ Conference four years ago. No one has suggested that the FIDIC 2017 forms of contract did not rectify some of the problems in the FIDIC 1999 forms, and in Edward Corbett’s articles,[1] ‘Cherry Picking FIDIC 2017,’ and ‘FIDIC 2017 – First Impressions of the 3-Kilo Suite’, he considered some of these changes. This new suite of contracts had, at best, a lukewarm reception when they were first reviewed, with some commentators complaining about the length of these new contracts and that the contracts had not taken account of criticisms that had been made by reviewers. This article looks at the twelve worst ‘gifts’ that FIDIC gave to us for Christmas 2017.
In December 2021 FIDIC issued its 2nd edition of the Green Book. It is not so much an update to the 1st edition as a new and improved, intermediate form of contract. FIDIC is promoting it as a simpler, user-friendly alternative to the FIDIC 2017 Red and Yellow Books, where significant contract administration and management resources are not needed. The Green Book 2nd edition is recommended to be used by the World Bank for projects up to US$ 10 million. The Green Book 1st edition was originally intended for projects of US $500,000 with no more than a 6-month duration. However, the Green Book 1st was sometimes used for larger projects with a duration of up to two years. The Green Book 2nd therefore takes over from where the Green Book 1st left off. This is to be welcomed. The FIDIC 2017 suite of contracts (Red/Yellow/Silver) is unsuitable for smaller projects where less administration is required. The Green Book 2nd will therefore fill a much-needed gap in the FIDIC rainbow and is likely to be attractive to both Contractors and Employers. This article looks at some of the key features of the Green Book 2nd.
Up until the spring of 2020, a FIDIC 1999 Sub-Clause 13.7 [Adjustments for Changes in Legislation][1] claim was just one of many issues to be resolved, for example, in a delay and disruption claim or a Cost claim. However, the focus it receives in the context of Covid-19 is drastically different. Many in the industry are using the changes in legislation provision to seek financial compensation in a situation that would otherwise potentially only attract an extension of time.[2] Awarding Cost for Covid-19 events regardless of the circumstances may seem to some (Contractors mostly, though there are Employers and Engineers who agree) like the appropriate thing to do, but whether it is correct according to the Contract is a different question.
An issue that often arises in international arbitrations involving the FIDIC forms of contract is whether a claimant's failure to: (a) go through the dispute resolution provisions; or (b) comply with a time-bar clause gives rise to a question of admissibility or jurisdiction. Put another way, if a claimant has failed to issue a notice of claim within 28 days or failed to refer a dispute to a DAB, does the arbitral tribunal have jurisdiction to make an award on the merits or should the arbitral tribunal make an award stating that it lacks jurisdiction?
FIDIC is concerned about its image. It says that heavily amending the FIDIC forms of contract impacts upon the FIDIC brand and that this is damaging FIDIC’s reputation. It seeks to address this with the introduction of five Golden Principles. But the Golden Principles are merely aspirational; they are not binding and have no contractual effect. Does this render them a pointless gesture ‘trying to hold back the tide’?
Is FIDIC’s new Emerald Book overly contractor-biased or does it offer pragmatic risk allocation for underground works? This article compares its benefits and risk distribution with the unamended FIDIC Yellow Book, especially regarding employer risks in claim-prone areas.
Much has been said about the new Red, Yellow and Silver Books 2nd Editions launched by FIDIC in December last year. The most obvious comment has been about their size, almost 50,000 words, which is some 60% longer than the 1999 forms. Although the 1999 forms were not perfect, most regular users seem to be agreed that they did not need 20,000 words to fix the issues. This consensus led this author to attempt to cherry-pick the good bits from the 2017 forms and to propose amendments to add the good ideas to the 1999 forms. The amendments apply to all three forms unless it is indicated otherwise.
MT Højgaard is an important English case, considering fitness for purpose obligations in design-and-build contracts. This article examines the Supreme Court’s analysis of a fitness for purpose obligation in Højgaard and whether it would be applied to FIDIC’s Yellow Book contracts.
Corbett & Co. has published its selection of the best bits of the FIDIC 2017 2nd Editions adapted for use with the 1999 forms. With many people put off by the 50,000+ words of the new editions, the FIDIC 1999 Upgrade will permit users to benefit from FIDIC’s new ideas and improvements.
FIDIC has launched the Second Editions of the Red, Yellow, and Silver Books, now over 50% longer than the 1999 forms. Key updates include more prescriptive processes, new time-bars, enhanced Dispute Boards, and a separate chapter on Disputes and Arbitration.
FIDIC is arguably the most widely used standard form of international construction contract but reported FIDIC cases are rare. Is it time for an increased publication of FIDIC cases? There are three categories of decisions arising out of FIDIC dispute resolution provisions: 1. Decisions of the Engineer or the Dispute Adjudication Board (DAB), which will generally not be published or reported to anyone other than the parties involved in the dispute. 2. Decisions of arbitral tribunals, which are not usually made public although this is subject to certain exceptions. 3. Decisions of national courts, which are a relatively rare occurrence for the reasons discussed below.
Read the full article here.
A previous article proposed that difficult questions arose from recent
